Last updated: 4th July 2025
Welcome to Karvex Limited. By accessing or using our website (/https://karveximited.com/), you agree to comply with and be bound by the following Terms and Conditions. Please read them carefully before using our site or engaging our services.
- Definitions
“We,” “us,” “our” refers to Karvex Limited.
“You,” “user,” “client” refers to any individual or entity using this website or engaging our services.
“Services” refers to all engineering, water infrastructure, consulting, project planning, design, and construction-related services offered by Karvex Limited. - Use of the Website
By using this website, you agree not to:
- Use it for any unlawful purpose.
- Attempt to gain unauthorized access to any part of the site.
- Copy, distribute, or exploit any content without written permission.
We reserve the right to modify or withdraw any part of the website or service without notice.
- Intellectual Property
All content on this website, including text, graphics, logos, images, and software, is the property of Karvex Limited unless otherwise stated. Unauthorized use or reproduction is strictly prohibited. - Services and Engagement
Engagement with Karvex Limited for any service is subject to:
- A formal written agreement or approved quotation.
- Payment terms as agreed in writing or in an invoice.
- Scope of work as defined in project documentation.
We reserve the right to reject or discontinue services in cases of non-payment, misuse, or breach of terms.
- Pricing and Payments
All prices are quoted based on the scope of work and are subject to change based on project requirements.
- Invoices must be paid according to the terms stated (e.g., advance payments, milestone-based payments).
- Late payments may incur additional charges or service suspension.
All financial transactions are in [insert currency, e.g., UGX or USD], unless stated otherwise.
- Subcontracting and Third Parties
Karvex Limited may engage subcontractors or third-party professionals for certain aspects of service delivery. We maintain responsibility for quality and oversight, unless otherwise agreed.
We are not liable for delays or defects caused by third-party services beyond our control.
- Limitation of Liability
While we strive for excellence in every project, Karvex Limited is not liable for:
- Indirect, incidental, or consequential damages.
- Losses due to external factors (e.g., weather, third-party delays, or site conditions).
- Client decisions based on incomplete or inaccurate information provided to us.
Our liability in any engagement is limited to the amount paid by the client for the specific service.
- Warranties and Guarantees
We provide services using industry best practices, but no guarantees are offered unless stated in writing. Any warranties from third-party suppliers or manufacturers are passed on as-is. - Termination
We reserve the right to suspend or terminate access to the website or our services if:
- These Terms and Conditions are violated.
- Misuse, abuse, or unlawful activity is detected.
Clients may also terminate service agreements as per the terms outlined in individual contracts.
- Privacy
Your use of our website and services is also governed by our Privacy Policy, which explains how we collect, use, and store your data. You can view it at: https://karveximited.com/privacy-policy/ - Governing Law
These Terms are governed by the laws of the Republic of Uganda. Any disputes shall be resolved in the courts of competent jurisdiction in Uganda. - Changes to These Terms
We may update these Terms from time to time. Continued use of the website or our services indicates your acceptance of any revised Terms. Please check this page periodically for updates.